3-8-2022 Kemmerer Gazette Legals


INVITATION FOR BID

Sealed proposals will be received for the Expand Snow Removal Equipment (SRE) Building project, addressed to Kemmerer City Hall, Kemmerer Municipal Airport, 220 State Hwy 233, Kemmerer, WY 83101 until 4:00 pm local time on March 30, 2022 , and then will be publicly opened and read. Bids received after the time fixed for the opening will not be considered.

A pre-bid meeting will be held online March 16, 2022 at 11:00 am, local time for those interested contractors, subcontractors, and suppliers. Bidders can access the pre-bid zoom meeting with the following link or zoom ID:  https://jubengineers.zoom.us/j/5825826666

The project consists of, but is not limited to,  site clearing and preparation, excavation and base placement, foundation placement, building erection, propane heater system modifications, electrical wiring and lighting, and other associated building work to extend an existing 24-ft wide bay of the Snow Removal Equipment (SRE) Building 15-ft to accommodate the Airport’s SRE Truck with Plow attachment mounted.

Digital copies of the Bidding Documents (including any Addenda) may be obtained from QuestCDN at www.questcdn.com upon payment of twenty-five dollars ($25.00). Log on to the website and enter Quest Project #8137054. Should you need assistance with this process, please contact QuestCDN at 952-233-1632. Partial sets of Bidding Documents will not be available from the Issuing Office.

Bids will only be accepted from registered planholders who have downloaded a set of Plans and Contract Documents from QuestCDN.com

Each bid must be accompanied by a certified check, cash, cashier’s check, or bid bond in an amount not less than 5% of the total bid.

CIVIL RIGHTS – TITLE VI

City of Kemmerer in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. §§ 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award.

The proposed contract is also under and subject to the following federal clauses:

• Affirmative Action,

• Government-wide Debarment and Suspension

• Government-wide Requirements for Drug-free Workplace

• Foreign Trade Restrictions

• Buy American Preference

• Disadvantage Business Enterprise Requirements as follows:

The Owner’s award of this contract is conditioned upon Bidder satisfying the good faith effort requirements of 49 CFR §26.53.

All required Federal Clauses including the labor provisions, and wage rates are included in the specifications and bid documents. Each bidder must supply all of the information required by the bid documents and specifications.

This project includes Federal funds and is subject to the wage provisions of Federal Davis-Bacon, and related acts.

Each bidder shall furnish the Statement of Bidders Pre-Qualifications to the OWNER with satisfactory evidence of their competency to perform the work contemplated with the bid.

The City of Kemmerer reserves the right to reject any and all proposals, waive any informalities, or irregularities, postpone the award of the Contract for a period not to exceed Ninety (90) days, and accept the proposal that is in the best interest of the City of Kemmerer. The award of the Bid is contingent upon the receipt of Federal funding.

Dated this 1st day of March, 2022.

PUBLISHED: March 1, 8, 15, 2022 03013

IN THE DISTRICT COURT OF LINCOLN COUNTY, WYOMING THIRD JUDICIAL DISTRICT

CIVIL NUMBER: CV-2022-1-DC

Mortgage Assets Management, LLC, Plaintiff,

    v.

Paula L Reel; Beverly June Copeland Jones, as executrix of the Copeland Revocable Trust; The Unknown Heirs and Devisees of James Parmen Copeland; The Unknown Heirs and Devisees of Pauline Copeland; and Secretary of Housing and Urban Development; and any person in possession,

Defendants.

NOTICE OF PUBLICATION

TO THE ABOVE-NAMED DEFENDANTS, THE UNKNOWN HEIRS AND DEVISEES OF JAMES PARMEN COPELAND:

DEFENDANTS LAST KNOWN ADDRESS: 1213 Strawberry Creek Private Road, Bedford, WY 83112

PLEASE TAKE NOTICE that the Plaintiff has filed with the Third Judicial District, Lincoln County, State of Wyoming, a Complaint for Judicial Foreclosure of property secured by a Mortgage.  This action pertains to the following property:

Real Property located at 1213 Strawberry Creek Private Road, Bedford, WY 83112, more particularly described as follows:

Lot 17 of Bridger Forest Ranch Subdivision, amended, according to the Official Plat thereof on file in the office of the Lincoln County Recorder, Kemmerer, Wyoming.

Plaintiff is requesting the following in its complaint:

A. Judgment quieting title in Paula L. Reel’s name as of the date the Quitclaim Deed recorded conveying title to her from the Copeland Trust.

B. Quiet Title Judgment confirming Defendants Beverly June Copeland Jones, as executrix of the Copeland Revocable Trust; The Estate of James Parmen Copeland and The Estate of Pauline Copeland hold no title or ownership interest in the property subject to this complaint.

C. Judgment in favor of Plaintiff on its claim for declaratory relief, declaring that Plaintiff is the Mortgagee of the Mortgage;

D. An order of sale and decree of foreclosure of the Property in accordance with Wyoming law, where (i) the Plaintiff is to provide such publication and notice as is required pursuant to W.S. § 1-18-101, (ii) the Plaintiff is permitted to be a purchaser at the foreclosure sale and is permitted to “credit bid” the amount owed to it, (iii) when any time for redemption has elapsed, the Sheriff or other officer conducting the sale shall execute a deed to the purchaser of the Property at the sale and that the purchaser be let into possession of the Property on production of said deed;

E. Judgment reforming the Mortgage as of its original recording to reflect the correct legal description of the property, described as follows:

Lot 17 of Bridger Forest Ranches Subdivision, amended, according to the Official Plat thereof on file in the office of the Lincoln County Recorder, Kemmerer, Wyoming.

F. Attorney’s fees and costs to Plaintiff in its enforcement of its rights and remedies prior to and during this litigation, including all fees incurred up and until the date of foreclosure; and 

G. Such other and further relief as the Court deems just and equitable under the circumstances.

YOUR RIGHTS MAY BE AFFECTED.  You should read this notice carefully and discuss them with your attorney, if you have one in this case.  If you do not have an attorney, you may wish to consult one.  Unless you file an answer or response or otherwise respond to the Complaint within thirty (30) days following the last date of publication of this Notice, a default judgment will be entered against you and Judgment will be entered.

Dated this 10 day of February, 2022

BY THE CLERK OF COURT:

/s/ Clerk of District Court

PUBLISHED: Feb. 22, March 1, 8, 15, 2022 02227

AMENDED NOTICE OF

PUBLIC COMMENT HEARING

(Issued February 25, 2022)

Pursuant to the Wyoming Administrative Procedure Act, Wyo. Stat. § 37-1-101, et seq., and the Wyoming Public Service Commission’s (Commission) Rules, notice is hereby given that the Commission will hold a Public Comment Hearing in Docket No. 20000-603-EA-21, the filing of Rocky Mountain Power’s (RMP) Integrated Resource Plan (IRP) for 2021.

This Public Comment Hearing, the second of three scheduled in this matter, will be held on Wednesday, March 23, 2022, at the Kemmerer City Council Chambers located at 220 State Highway 233 from 5:00 pm to 7:00 pm. It will be conducted in accordance with the Wyoming Administrative Procedure Act and the Commission’s Rules.

1. All interested persons are encouraged to attend the public hearing which will be conducted in accordance with the Wyoming Administrative Procedure Act, Wyoming Public Service Commission Rules, and subject to any applicable national, state or local public health related orders or directives. All interested persons may appear and be heard, in person, by video conference, or through counsel appearing in person or by video conference.

Attend by Zoom Meeting and actively participate at:

https://us02web.zoom.us/j/82669586649

Any updates will be announced at: https://psc.wyo.gov/home/hot-topics.

The number of people in the Kemmerer City Council Chambers and auxiliary spaces will be limited to maintain recommended physical distance between individuals. If attendance is greater than can be accommodated in the Council Chambers, consistent with physical distancing guidelines, the building lobby and a conference room will be available as waiting areas. Attendees are encouraged to wear face masks or coverings. Facemasks will be available at this Public Comment Hearing.

If you wish to attend the hearing and you require reasonable accommodation for a disability, please contact the Commission at (307) 777-7427 (Voice or TTY) in Cheyenne during regular business hours or write them at 2515 Warren Avenue, Suite 300, Cheyenne, Wyoming 82002, to make arrangements. Communications impaired persons may also contact the Commission by accessing Wyoming Relay (TTY) by dialing 711. Please mention Docket No. 20000-603-EA-21 in your correspondence.

Dated: February 25, 2022.

PUBLISHED: March 1, 2022 03014

IN THE DISTRICT COURT OF LINCOLN COUNTY, WYOMING THIRD JUDICIAL DISTRICT

CIVIL NUMBER: CV-2022-1-DC

Mortgage Assets Management, LLC, Plaintiff,

    v.

Paula L Reel; Beverly June Copeland Jones, as executrix of the Copeland Revocable Trust; The Unknown Heirs and Devisees of James Parmen Copeland; The Unknown Heirs and Devisees of Pauline Copeland; and Secretary of Housing and Urban Development; and any person in possession,

Defendants.

NOTICE OF PUBLICATION

TO THE ABOVE-NAMED DEFENDANTS, THE UNKNOWN HEIRS AND DEVISEES OF PAULINE COPELAND:

DEFENDANTS LAST KNOWN ADDRESS: 1213 Strawberry Creek Private Road, Bedford, WY 83112

PLEASE TAKE NOTICE that the Plaintiff has filed with the Third Judicial District, Lincoln County, State of Wyoming, a Complaint for Judicial Foreclosure of property secured by a Mortgage.  This action pertains to the following property:

Real Property located at 1213 Strawberry Creek Private Road, Bedford, WY 83112, more particularly described as follows:

Lot 17 of Bridger Forest Ranch Subdivision, amended, according to the Official Plat thereof on file in the office of the Lincoln County Recorder, Kemmerer, Wyoming.

Plaintiff is requesting the following in its complaint:

A. Judgment quieting title in Paula L. Reel’s name as of the date the Quitclaim Deed recorded conveying title to her from the Copeland Trust.

B. Quiet Title Judgment confirming Defendants Beverly June Copeland Jones, as executrix of the Copeland Revocable Trust; The Estate of James Parmen Copeland and The Estate of Pauline Copeland hold no title or ownership interest in the property subject to this complaint.

C. Judgment in favor of Plaintiff on its claim for declaratory relief, declaring that Plaintiff is the Mortgagee of the Mortgage;

D. An order of sale and decree of foreclosure of the Property in accordance with Wyoming law, where (i) the Plaintiff is to provide such publication and notice as is required pursuant to W.S. § 1-18-101, (ii) the Plaintiff is permitted to be a purchaser at the foreclosure sale and is permitted to “credit bid” the amount owed to it, (iii) when any time for redemption has elapsed, the Sheriff or other officer conducting the sale shall execute a deed to the purchaser of the Property at the sale and that the purchaser be let into possession of the Property on production of said deed;

E. Judgment reforming the Mortgage as of its original recording to reflect the correct legal description of the property, described as follows:

Lot 17 of Bridger Forest Ranches Subdivision, amended, according to the Official Plat thereof on file in the office of the Lincoln County Recorder, Kemmerer, Wyoming.

F. Attorney’s fees and costs to Plaintiff in its enforcement of its rights and remedies prior to and during this litigation, including all fees incurred up and until the date of foreclosure; and 

G. Such other and further relief as the Court deems just and equitable under the circumstances.

YOUR RIGHTS MAY BE AFFECTED.  You should read this notice carefully and discuss them with your attorney, if you have one in this case.  If you do not have an attorney, you may wish to consult one.  Unless you file an answer or response or otherwise respond to the Complaint within thirty (30) days following the last date of publication of this Notice, a default judgment will be entered against you and Judgment will be entered.

Dated this 10th day of February, 2022

BY THE CLERK OF COURT:

/s/ Clerk of District Court

PUBISHED: Feb. 22, March 1, 8, 15, 2022 02228

NOTICE OF APPLICATION FOR TAX DEED

TO: Andrew A Novak 16,7 Park Ave.

Puyallup WA 98372-4713

YOU ARE HERBY NOTIFIED of the following, pursuant to W.S. 39-13-108(e).

The following described property situated in Lincoln County, Wyoming is the subject of this notice: LB TS B 23 L 17-20 T26 R113 S2

Said property was subject to, and assessed for, taxation for the year of 2016.

It was assessed and taxed in the name of Andrew A. Novak.

3. On 25 July 2017, Gerald R. Grove, Jr., purchased said property at public sale at the Courthouse in Kemmerer, Wyoming, for the sum of $108.91, said sum being the then unpaid assessed taxes, accumulated interest and costs. On that day, Gerald R. Grove, Jr., received a copy of Certificate of Purchase, # 105059 from the Lincoln County Treasurer.

4. Pursuant W.S. 39-13-108(e) the legal owner of said real property has until the date of application for tax deed in which to redeem the same from Gerald R. Grove Jr. Unless redeemed within the span oftime the legal owner’s right of redemption expires. On or after 1 July 2022, Gerald R. Grove, Jr., will be entitled to apply for and receive a deed to such property as provided in W. S. 39-13-108(e)(v).

5. Application for a tax deed will be made on 1 July 2022. The amount required to redeem is as provided in 39-13-108(e). The amount for which the property was sold at tax sale was $108.9l. In addition, Gerald R. Grove, Jr., paid taxes assessed on the property for tax years, 2017, 2018, 2019, 2020, 2021.

Dated this 28th day of February 2022

Gerald R. Grove, Jr.

2007 W. Rocky Road

Salt Lake City., UT 84129

PUBLISHED: March 8, 15, 22, 2022 03081

WYOMING DEPARTMENT OF TRANSPORTATION

CHEYENNE, WYOMING

NOTICE OF ACCEPTANCE OF AND

FINAL SETTLEMENT FOR HIGHWAY WORK

Notice is hereby given that the State Transportation Commission of Wyoming has accepted as completed according to plans, specifications and rules governing the same work performed under that certain contract between the State of Wyoming, acting through said Commission, and Reiman Corp., The Contractor, on Highway Project Number 1207002 in Lincoln County, consisting of bent cap replacement and miscellaneous work, and the Contractor is entitled to final settlement therefore; that the Director of the Department of Transportation will cause said Contractor to be paid the full amount due him under said contract on April 11, 2022.

The date of the first publication of this Notice is March 1, 2022.

STATE TRANSPORTATION COMMISSION OF WYOMING

Pam Fredrick

Senior Budget Analyst

Budget Program

PUBLISHED: March 1, 8, 15, 2022 03011

CITY COUNCIL PROCEEDINGS

The Kemmerer City Council met in regular session this 14th day of February, 2022, at 7 p.m. in the City Council Chambers, City Hall, Kemmerer, Wyoming.  The Pledge of Allegiance was recited.  Present on roll call were Mayor William Thek, Councilmember Robert Bowen, Councilmember Bill Price, Councilmember Eric Rudy, and Councilmember Jamie Thornock.  Councilmember Dale Hicks and Councilmember Mark Quinn were absent

Motion was made by Councilmember Price to excuse the absences of Councilmember Hicks and Councilmember Quinn; seconded by Councilmember Rudy and unanimously approved by Council present.

Motion was made by Councilmember Bowen to approve the agenda as presented with the addition of item (E) under New Business, Support Letter for Rocky Mountain Power Gateway South project; seconded by Councilmember Thornock and unanimously approved by Council present.

PRESENTATIONS:

Dave McConkie was presented with a Years of Service Award.

PUBLIC HEARING:

The public hearing was opened at 7:06 pm for comments on the new Bootleggers LLC Restaurant Liquor License application.  No comments were made.  Public hearing closed at 7:07 pm.

VISITOR’S COMMENTS AND PETITIONS:

No comments were made.

CONSENT AGENDA:

Motion was made by Councilmember Bowen to approve the items on the consent agenda as presented; seconded by Councilmember Thornock and unanimously approved by Council present. Those items were:

(a) approval of the minutes of January 24, 2022, as presented;

(b) approval of the payment of the bills and payroll and ACH payments as presented:

15332 Val Inc. $9,603.00 15333 UMWA $264.80

15334 Wyoming Retirement System 26,910.54 15337 Bailey, Richard 60.50

15336 All West Communications 213.90 15339 City of Kemmerer Acct. 480.00

15338 City of Kemmerer 1.444.86 15341 Denison, Lynnae 1,250.00

15340 Cowboy State Trucking 306.25 15343 Durgin, Shane & Carolyn 60.50

15342 Dominion Energy 42.84 15345 First Bank of Wyoming 5,358.41

15344 Evans, Mike 565.48 15347 Freedom Mailing Services 798.93

15346 Floyd’s Truck Center WY 501.90 15349 Gunter’s Tire and Lube Shop 200.00

15348 Giacoletto. Christopher & Nat 60.50 15351 Hansen, Dustin 590.00

15350 Hagge, Regg & Danielle 60.50 15353 Holiday Magic Boutique 120.00

15352 Harris Law Office, PC 1,200.00 15355 Intermountain Fire Protection 100.00

15354 Independent Fee Estimates 2,140.00 15357 Jones Simkins LLC 3,600.00

15356 Interwest Supply Company 3,357.96 15359 Kemmerer Gazette 228.98

15358 JUB Engineers 2,814.50 15361 Lincoln County Sheriff’s Office 2,420.00

15360 Lincoln County Landfill 8,406.00 15363 Mayer, Donna & William 60.50

15362 LogMeIn Communications 399.79 15365 McGuire, Vincent 60.50

15364 Mayo, Robert & MaryBeth 60.50 15367 Netwize 1,623.25

15366 Mountain Peak Builders 44,148.50 15369 One-Call of Wyoming 53.50

15368 Norco Inc 13.64 15371 Rocky Mountain Power 9,927.91

15370 Pewag Traction Chain Inc 1,001.27 15373 Shums Coda Associates 480.00

15372 Rodriguez, Dakota & Victor 60.50 15375 Verizon Wireless 600.48

15374 Val Inc 9,603.00 15377 VSP of Wyoming 207.38

15376 Viviano’s Concrete 500.00 15379 Wex Bank 1,719.50

15378 WAMCAT 150.00 15381 Winnelson 114.91

15380 Wheeler Machinery Co, Inc. 98.00 15383 WYDOT-Financial Services 44.29

15382 WRPA 50.00 01/26/22 4th Qtr Workmans Comp-ACH 9,312.47

15384 Wyoming Community Foun 12,232.40 02/02/22 Federal Tax Deposits-ACH 11,255.33

01/31/22 Secure Instant Pay-ACH 19.95 02/02/22 Orchard Trust-ACH 725.00

02/02/22 Payroll Deposits-ACH 38,568.81 02/02/22 ICMA-ACH 50.00

(c) authorize staff to apply for a grant from Lincoln County Recreation Commission in the amount of $7,170.98;

(d) authorize four nights for retail liquor establishments to be open all night in 2022;

OLD BUSINESS:

None

NEW BUSINESS:

Motion was made by Councilmember Bowen to approve the Liquor License Application for Bootlegger’s LLC, seconded by Councilmember Rudy and unanimously approved by council present.

Motion was made by Councilmember Bowen to approve the Vickery Lot Line Vacation; seconded by Councilmember Thornock and unanimously approved by council present.

Motion was made by Councilmember Bowen to approve the Jamison Lot Line Vacation; seconded by Councilmember Price and unanimously approved by council present.

Motion was made by Councilmember Bowen to approve the RFP for a new police vehicle with specs to be determined by staff at a later date; seconded by Councilmember Price and unanimously approved by council present.

Motion was made by Councilmember Bowen to approve staff to draft a letter of support for the Rocky Mountain Power Gateway South project; seconded by Councilmember Price. The mayor then called for the question.  Those voting “Yea” were Mayor Thek, Councilmember Bowen, Councilmember Price and Councilmember Rudy. Councilmember Thornock voted “Nay.”  Motion carried.

COMMENTS:

Brian Muir, City Administrator, made comments.

Motion was made by Councilmember Bowen to recess into executive session to discuss property; seconded by Councilmember Rudy and unanimously approved by Council; 7:12 p.m.

Motion was made by Councilmember Bowen to convene into executive session; seconded by Councilmember Price and unanimously approved by Council; 7:17 p.m.

Motion was made by Councilmember Bowen to adjourn executive session; seconded by Councilmember Price and unanimously approved by Council; 7:44 p.m.

Motion was made by Councilmember Bowen to reconvene into regular session; seconded by Councilmember Price and unanimously approved by Council; 7:47 p.m.

Motion by Councilmember Bowen to direct staff to begin the process of getting appraisals on all City owned property on the Triangle; seconded by Councilmember Price and unanimously approved by Council present. 

There being no further business before the Council, Councilmember Price made a motion to adjourn the meeting; seconded by Councilmember Thornock and unanimously approved by Council; 7:50 p.m.

CITY OF KEMMERER, WYOMING

     BY: WILLIAM J THEK, MAYOR

ATTEST: NATASIA DIERS

CITY CLERK-TREASURER

PUBLISHED: March 8, 2022 03083

ADVERTISEMENT FOR BIDS

Notice is hereby given that Lincoln County Board of County Commissioners are requesting bids for the

2022 County Road Dust Suppression consisting of the following items:   

2,050  TONS OF MAGNESIUM CHLORIDE FOR DUST SUPPRESSION

Successful Contractor will be required to furnish all supervision, technical, personnel, labor, materials, machinery, tools, equipment, and services, including utility and transportation services to perform and complete all applications on all specified roads as defined in the bid documents. 

The CONTRACT DOCUMENTS may be examined at, or obtained from, the Lincoln County website with a $15 download fee at: 

http://www.lcwy.org/departments/planning_and_engineering/  and click on Bid Docs

Sealed Bids will be received at the Kemmerer Planning & Engineering Office, 925 Sage Ave, Suite 201, Kemmerer, Wyoming, 83101 until 2:00 P.M. local time, Thursday, March 31, 2022  Bids should be marked on the outside “2022 County Road Dust Suppression ” with the name and address of the bidder. Amy Butler, County Engineer, is the primary contact for this project (307-877-2104).

Public opening of the bids will be on Thursday, March 31, 2022 at 2:00 P.M. located at the Lincoln County Planning & Engineering Office, 925 Sage Ave, Suite 201, Kemmerer, Wyoming.  Bidders are welcome to attend. 

This project is partially funded using Federal Grant Funds. Therefore, all Federal Requirements associated with the use of these funds must be followed for this project. 

All bids must be accompanied by either a certified check, cashier’s check drawn on an acceptable bank, or an acceptable BID BOND, executed by an approved Surety Company, in an amount not less than five percent (5%) of the total sum of the bid.  The check or bond shall be made payable to Lincoln County and shall be forfeited as liquidated damages if the bidder, upon the letting of the contract to him, fails to enter into the contract within thirty (30) days after it is presented to him for that purpose or fails to proceed with the performance of the contract in a timely manner.

All projects over $150,000.00 shall be bonded therefore the successful bidder shall provide a 100% performance and payment bond.  All projects over $7,500.00 or less than $150,000.00 requires a form of guarantee as approved by the County

The Board of the County Commissioners of Lincoln County hereby notifies all bidders that minority business enterprises will be afforded full opportunity to submit bids in response to the invitation and will not be discriminated against on the grounds of race, color, sex, creed, or national origin. 

Lincoln County reserves the right to accept or reject any items or all items, any part or all parts, any section or all sections, any bid or all bids as stated in the specifications to waive any irregularities or informalities, or to re-bid or re-advertise for bids if it is determined to be necessary or desirable and reserve the right to let the bid in any manner it sees fit. 

LINCOLN COUNTY, WYOMING

(s) Robert E. King, Chairman

PUBLISHED: March 8,15,22, 2022 03084

PUBLICATION OF GROSS SALARIES

School District No. One, Lincoln County - March 2022

Pursuant to Wyoming Statute 21-3-110 - Duties of board of trustees, individual yearly gross salary payments shall be published each year.  Each individual annual gross salary shall be identified by category and each individual salary shall be  published as a gross dollar amount without identification other than by category.

Total

Annual Total Annual

Gross No. Gross

Category Salary Personnel Salaries

141,000.00 1 $141,000.00

Coordinator/Directors 71,150.00 63,684.00 62,500.00

47,500.00 22,500.00 4.25 $267,334.00

Instructional Facilitator

66,105.00 1 $66,105.00

Building Administrators 96,000.00 93,000.00

67,500.00 36,375.00 3.25 $292,875.00

Teacher: Elementary

65,100.00 64,750.00 64,500.00 23 $1,292,337.00

62,300.00 61,950.00 61,750.00

60,550.00 60,200.00 59,850.00 59,150.00

58,450.00 57,750.00 57,750.00 56,350.00

55,750.00 55,000.00 55,000.00 54,000.00

53,000.00 52,000.00 51,000.00 50,000.00

16,187.00

Teacher: Secondary

75,950.00 71,050.00 70,700.00 18.5 $1,138,911.00

69,650.00 67,900.00 66,500.00

66,500.00 65,450.00 63,700.00

63,000.00 58,100.00 56,350.00

54,750.00 53,250.00 53,000.00

52,000.00 48,562.00 46,124.00

36,375.00

Teacher: Special Education

73,150.00 68,250.00 63,700.00 6 $385,800.00

62,750.00 60,550.00 57,400.00 Support Professional 69,650.00 66,150.00 66,150.00 5   $318,850/00

59,500.00 57,400.00

Administrative Assistant/Clerk

41,718.00 40,559.00 37,202.00 10.25 $324,508.00

34,275.00 32,972.00 31,350.00

29,228.00 27,588.00 10,599.00 2,860.00

Custodian:

44,892.00 35,496.00 33,408.00 5.5 $186,275.00

32,866.00 31,914.00 7,699.00 Food Service Staff

23,680.00 18,454.00 15,332.00 8 $97,177.00

13,829.00 10,175.00 7,010.00

4,673.00 4,024.00

Operations and Maintenance

56,376.00 44,370.00 29,369.00 4 $152,109.00

21,994.00

Paraprofessionals

30,294.00 29,172.00 28,006.00 30 $580,867.52

28,006.00 27,348.75 26,437.13

25,759.25 23,725.63 23,047.75

22,708.81 22,440.00 22,369.88

21,353.06 21,014.13 21,014.13

20,336.00 18,303.00 18,303.00

17,964.00 17,963.00 17,625.00

16,947.00 16,947.00 16,947.00

13,046.00 12,120.00 7,555.00

7,153.00 5,423.00 1,539.00 Transportation

53,766.00 31,080.00 17,806.25 7 $154,788.00

16,997.00 16,881.25 9,157.50

9,100.00

Coaches 8.00 $63,700.00

Assistant Coaches 28.00 $86,218.00

Sponsors 32.00 $35,800.00

District Total 194.75 $5,584,654.52

PUBLISHED: March 8, 2022 03082

NOTICE OF APPLICATION FOR TAX DEED

David Galli

Box 1966

Fort Bragg, CA 95437

YOU ARE HEREBY NOTIFIED of the following, pursuant to W.S. 39-13-108.

1. The following described property, situated in Lincoln County, Wyoming is subject of this notice:  LB TS B 04 L 01 02 14 15 T26 R113 S2- Lots 1, 2 & 14, 15, Parcel # 26130210400400, R0005471, Total .1377 Acres, located in Lincoln County, WY.

2. Said property was subject to, and assessed for, taxation for the year of 2016.   It was assessed and taxed in the name of David J Galli.

3. On July 25 2017, Edwin L Brower Trust purchased said property at public sale at the Courthouse in Kemmerer, Wyoming, for the sum of $71.84, said sum being the then unpaid assessed taxes, accumulated interest and costs.  On that day, Edwin L Brower received a copy of the Certificate of Purchase, #104885 from the Lincoln County Treasurer. 

4. Pursuant to W.S 39-13-108 the legal owner of said real property has until the date of application for tax deed in which to redeem the same from Pamla Sibert, trustee of the Edwin L Brower Trust.  Unless redeemed within the span of time the legal owner’s right of redemption expires.  On or after March 15, 2022, Pamla Sibert will be entitled to apply for and receive a deed to such property as provided in W.S. 39-13-108.

5. Application for a tax deed will be made on March 15, 2022.  The amount required to redeem is as provided in W.S. 39-13-108. The amount for which the property was sold at tax sale was $ 71.84.  In addition, $ 161.32 paid taxes assessed on the property for tax years 2016, 2017, 2018, 2019, 2020 and 2021.

DATED this 22nd day of February 2022

  Pamla Sibert Certificate of Purchase Holder

  2838 Co Rd 217

  Fort Bridger, WY 82933

PUBLISHED: Feb. 22, March 1, 8, 15, 2022 02226

NOTICE OF APPLICATION FOR TAX DEED

Allen Kesler

Box 158

Opal, WY 83124

YOU ARE HEREBY NOTIFIED of the following, pursuant to W.S. 39-13-108.

1. The following described property, situated in Lincoln County, Wyoming is subject of this notice:  OPAL OT B 07 L 05 T21 R114 S26-Lot 5, Parcel # 21142631005500, R0000767, BLK 07, Total .2203 Acres, located in Lincoln County, WY.

2. Said property was subject to, and assessed for, taxation for the year of 2016.   It was assessed and taxed in the name of Allen Kesler.

3. On July 25, 2017, Edwin L Brower Trust purchased said property at public sale at the Courthouse in Kemmerer, Wyoming, for the sum of $56.36, said sum being the then unpaid assessed taxes, accumulated interest and costs.  On that day, Edwin L Brower received a copy of the Certificate of Purchase, #104886 from the Lincoln County Treasurer. 

4. Pursuant to W.S 39-13-108 the legal owner of said real property has until the date of application for tax deed in which to redeem the same from Pamla Sibert, trustee of the Edwin L Brower Trust.  Unless redeemed within the span of time the legal owner’s right of redemption expires.  On or after March 15, 2022, Pamla Sibert will be entitled to apply for and receive a deed to such property as provided in W.S. 39-13-108.

5. Application for a tax deed will be made on March 15, 2022.  The amount required to redeem is as provided in W.S. 39-13-108. The amount for which the property was sold at tax sale was $ 56.36.  In addition, $ 82.87 paid taxes assessed on the property for tax years 2016, 2017, 2018, 2019, 2020 and 2021.

DATED this 22nd day of February 2022

Pamla Sibert Certificate of Purchase Holder

2838 Co Rd 217

Fort Bridger, WY 82933

PUBLISHED: Feb. 22, March 1, 8, 15, 2022 02225

UNITED STATES OF AMERICA

FEDERAL ENERGY REGULATORY COMMISSION

PacifiCorp Project No. 15247-000

NOTICE OF PRELIMINARY PERMIT APPLICATION ACCEPTED FOR FILING AND SOLICITING COMMENTS, MOTIONS TO INTERVENE, AND COMPETING APPLICATIONS

(February 7, 2022)

On October 13, 2021, PacifiCorp filed an application for a preliminary permit, pursuant to section 4(f) of the Federal Power Act, proposing to study the feasibility of the South Fork Pumped Storage Project (South Fork Project or project) to be located near Lake Viva Naughton, Lincoln County, Wyoming.  The sole purpose of a preliminary permit, if issued, is to grant the permit holder priority to file a license application during the permit term.  A preliminary permit does not authorize the permit holder to perform any land-disturbing activities or otherwise enter upon lands or waters owned by others without the owners’ express permission.

Two alternatives are being considered for the South Fork Project.  Alternative 1 would consist of the following: (1) an upper reservoir approximately 3.5 miles east of Lake Viva Naughton with a surface area of 210 acres and a storage volume of approximately 3,348 acre-feet created by a 1,870-foot-long, 340-foot-high embankment dam; (2) a new intake/outlet on Lake Viva Naughton, which will serve as the lower reservoir; (3) a 4.2-mile-long steel penstock with a diameter of 23-feet connecting the upper reservoir with the powerhouse/pump station; (4) a 50-foot-long, 150-foot-wide concrete powerhouse/pump station located on the eastern shoreline of Lake Viva Naughton containing three 167-megawatt generating/pumping units; (5) a 4.4-mile, 345-kilovolt transmission line and new substation interconnecting to PacifiCorp’s Jim Bridger-Populus #2 transmission line; and (6) appurtenant facilities. 

Alternative 2 would consist of the same facilities described in alternative 1 except: (1) the upper reservoir would have a surface area of 85 acres and a storage volume of approximately 3,604 acre-feet created by a 1,035-foot-long, 310-foot-high embankment dam; (2) the upper reservoir would connect to the powerhouse/pump station by a 3.8-mile-long, 23-foot-diameter steel penstock; (3) the transmission line would be 2.2 miles in length connecting to a new substation at same transmission line. 

The estimated annual generation of the South Fork Project would be 1,460 gigawatt-hours.

Applicant Contact:  Tim Hemstreet, Managing Director, Renewable Energy Development, PacifiCorp, 825 NE Multnomah, Suite 1800, Portland, OR 97232; email: [email protected]; phone: (503) 813-6170.

FERC Contact:  Kristen Sinclair; email: [email protected]; phone: (202) 502-6587.

Deadline for filing comments, motions to intervene, competing applications (without notices of intent), or notices of intent to file competing applications:  60 days from the issuance of this notice.  Competing applications and notices of intent must meet the requirements of 18 C.F.R. § 4.36. 

The Commission strongly encourages electronic filing.  Please file comments, motions to intervene, notices of intent, and competing applications using the Commission’s eFiling system at http://www.ferc.gov/docs-filing/efiling.asp.  Commenters can submit brief comments up to 6,000 characters, without prior registration, using the eComment system at http://www.ferc.gov/docs-filing/ecomment.asp.  You must include your name and contact information at the end of your comments.  In lieu of electronic filing, you may submit a paper copy.  Submissions sent via the U.S. Postal Service must be addressed to:  Kimberly D. Bose, Secretary, Federal Energy Regulatory Commission, 888 First Street NE, Room 1A, Washington, DC 20426.  Submissions sent via any other carrier must be addressed to:  Kimberly D. Bose, Secretary, Federal Energy Regulatory Commission, 12225 Wilkins Avenue, Rockville, Maryland 20852.  The first page of any filing should include docket number P 15247-000.   

More information about this project, including a copy of the application, can be viewed or printed on the “eLibrary” link of Commission’s website at http://www.ferc.gov/docs-filing/elibrary.asp.  Enter the docket number (P-15247) in the docket number field to access the document.  For assistance, contact FERC Online Support.

Kimberly D. Bose,

Secretary.

PUBLISHED: Feb. 15, 22, March 1, 8, 2022 02152

Advertisement